Tag: National Consumer Disputes Redressal Commission
![](https://www.indialaw.in/wp-content/uploads/2024/06/Builders-Cant-Excuse-Delay-in-Construction-Due-to-Payment-Issues-600x324.png)
Builders Cannot Use The Excuse Of Failure Of Timely Payment By Allottee When There Is A Delay In Construction Work
INTRODUCTION The Hon’ble National Consumer Disputes Redressal Commission (“NCDRC”), New Delhi on 3rd June 2024, in the case of M/s. Puri Construction Pvt. Ltd. v. Gurudarshan Singh and Anr[i], upheld the judgement passed by the
![Supreme Court Reiterates Duty of Care in Medical Negligence Case](https://www.indialaw.in/wp-content/uploads/2024/03/Supreme-Court-Reiterates-Duty-of-Care-in-Medical-Negligence-Case-600x324.png)
Supreme Court Reiterates Duty of Care in Medical Negligence Case
This judgementi concerns a medical negligence case where a 13-year-old boy, Master Irshad, lost vision in his right eye following a cataract surgery performed by the respondents. The District Consumer Disputes Redressal Commission (“DCDRC”) initially
![Airlines shall be held liable for default in the services promised by its Agent: Supreme Court](https://www.indialaw.in/wp-content/uploads/2023/11/Airlines-shall-be-held-liable-for-default-in-the-services-promised-by-its-Agent-Supreme-Court-600x324.png)
Airlines shall be held liable for default in the services promised by its Agent: Supreme Court
The Hon’ble Supreme Court (“SC”) in a recent notable judgment held that the Airlines shall be bound by the time schedule promised by its agent. In the instant case the Appellant, Rajasthan Art Emporium booked
![](https://www.indialaw.in/wp-content/themes/Nextline_V5-main/images/default.jpg)
Buyer’s right to refuse possession of flat upheld in case of delay in construction by developer
By Varsha G. Subramanian In a recent case[1], the National Consumer Disputes Redressal Commission (“Commission”) disposed off three complaints regarding inordinate delay in construction of the projects in favour of flat buyers. The Complainants had
![](https://www.indialaw.in/wp-content/themes/Nextline_V5-main/images/default.jpg)
Burning one’s fingers
By Dr. Subodh Sirur On a midnight, a leading gynecologist was attending a labor case in his hospital. He was the only senior doctor present in the hospital at that time. Suddenly, a three year
- Arbitration and Conciliation
- Banking and Finance
- Bankruptcy Code – Public Announcements
- Civil
- Commercial litigation
- Commercial/Corporate
- Criminal
- Cyber Law
- Debt Recovery
- Food
- IL News
- Infrastructure
- Insolvency & Bankruptcy
- Insurance
- Intellectual Property Rights
- International
- Labour
- Law
- Medico-Legal
- Negotiable Instrument
- NRI Laws
- Policy
- Power
- Real Estate
- Tax